Cite as: Digby Woodworkers Ltd. v. Basin Place Ltd., 1982 NSCO 1
:_979
c. D. i~o. :.oc9
IN Th~ COGNTY
COURT
OF
DISTRICT NuMBER THRE~
BETWEEN:
DIGBY WOODWORKERS
LIMITED
PLAINTIFF
-
and -
BASIN PLACE LIMITED
DEFENDANT
HEARD:
At Digby, Nova Scotia, the 10th day of
February, A.O. 1982 and the 16th day of
February, A.O. 1982.
BEFORE:
His Honour Judge Peter Nicholson, J.C.C.
DECISION:
The 28th day of September, A.D. 1982
COUNSEL:
W.
Michael Cooke, Esq., for the Plaintiff
Charles E. Haliburton, Q.C., for the Defendant
-
1
NICHOLSON, J.C.C.
The Plaintiff was in the business of a
general contractor and at times material hereto Lawrence K.
Banks
Digby was the President of the Company and super
vised the contract work on a building known as Basin Place
located on Water Street in the Town of Digby, Nova Scotia,
and owned by the Defendant.
The work in question consisted of renovating
a portion of the building to make it suitab
for dental
offices and a law office in that phase of the renovation that
was material to this action.
The Defendant paid to the Plaintiff for work
done and materials provided, the sum of $70,000.00, plus
$2,147.66 for extras.
The
Plaintiff now claims the further
sum of $16,049.57 for the balance of the work it had per
formed.
The Defendant counter-claimed against the Plaintiff
for damages for defective materials and workmanship, as a
result of which it denies that it owes the Plaintiff any
money and claims general damages for the defects complained
of, and delays sustained.
Mr. Lawrence Banks testified that he had
-
2
many years of experience as a carpenter and plumber and
that he prepared the estimates that were tendered to the
Defendant, which were produced as Exhibits 2, 3, 4 and 5
at the trial.
Photocopies of these estimates are appended
hereto as Appendix No.1 and they total $44,446.72 with
certain reservations as detailed in the tender documents.
It should be noted that plumbing and electrical work was
not included in the tender prices nor was crackfilling in
the offices.
The estimates were accepted.
Plans and specifi
cations
of the work had been provided to the Plaintiff by
the Defendant.
Apparently the work commenced in the month
of March, 1978, and before the job was finished Mr. Banks
sold out his shares in the Plaintiff Company
and Andrew
Brooks became President of the Plaintiff Company and took
Banks' place in charge of the work.
He had 30 years experience
as a carpenter.
The first complaint of the Defendant Company
is that the plans given by the Defendant to the Plaintiff
designating the work to be done specified that the ceilings
in the dental offices were to be 9 feet high, save and
excepting the waiting room which was to be 8 feet.
Dr. Harold
Boudreau who was to be a tenant of the dental offices stated
that he visited the premises shortly after the workmen commenced
-
3
to put up the dropped ceiling and just assumed that it was
9 feet high.
The next time Dr. Boudreau went to the premises,
which he thought was probably the next day, he discovered
that the office ceiling was in fact only 8 feet high.
He
felt that it would not be practical for him to bring down
that ceiling one more foot as he wanted to do in the waiting
room because that would mean it would only be 7 feet high
there, which was unacceptable.
In these circumstances Boudreau
said he agreed to leave all the ceilings at 8 feet presumably
because he was anxious to get into the premises and did not
want further delay.
There can be no doubt but that the height
of the ceiling was a departure from the plans and that the
Defendant feels that it was deprived of some desirable ascetic
feature because of this error.
For this item I allow the
Defendant a credit of $1,000.00
with respect to the ceilings of the whole
premises, the Defendant claimed that the dropped type of
ceilings, consisting of suspension wires, T-bars and tiles,
were unsatisfactory on two grounds.
First of all, it was
known by the Plaintiff's workmen that a sprinkler system
was to be installed in the premises.
A company from Halifax
was to come to do the work and to install the necessary
-
4
plumbing and sprinkler heads.
There can be no doubt from
the evidence that the Defendant wanted to get the work done
for i~s tenants as soon as possible.
There was considerable
pressure to get the ceilings up promptly; asa result of this
the ceilings were erected by the time the sprinkler people
came.
Of course many of the tiles had to be removed to allow
the workmen to install the system and as a result there was
damage done to the T-bar system and some of the tiles were
soiled and broken.
Some of these were replaced at the request
of Dr. Boudreau.
It is my opinion that the Plaintiff company
c~nnot be condemned for what happened to those ceilings as a
result of the failure of the Defendant to phase in properly
the work of the sprinkler people.
Secondly, Mr. Brooks testified that the
material used to put up the ceiling was supplied by Weldwood
Manufacturing Company being 2 feet by 4 feet rectangular
ceiling tiles.
Mr. Martin Giddy was the architect that pro
duced the plans of the work to be done.
He testified that the
plans called for the installation of Cellotex tiles.
Mr.
Robert Purdy,a general contractor and President of Baycrest
Limited, testified that only Guildfords Limited of Halifax
could supply the Cellotex tiles and in his view they should
also have installed them because the specifications spel
it out that "the tiles are to be installed by the supplier".
-
5
As it is apparent that the Defendant had knowledge of the
fact that the Plaintiff was installing the tiles, and did
nothing to stop the installation I find that there was tacit
approval that the Plaintiff should put up the ceilings although
there was no approval that the quality of the tile should be
other than that specified.
I find that the difference in
the price of the tiles specified and that which was installed
was $1,155.90.
The next complaint of a major nature was
that the door casings and some window casings, moldings and
baseboards were of rough spruce finish.
Mr. Brooks described
this wood as "paint grade pine".
Having viewed the premises
I
am satisfied that the material was not of an acceptable
standard and certainly was not what the witness Purdy described
as finish pine.
He pointed out that the plans called for
adherence to the National Building Code and the use of good
construction standards for material.
Purdy said the National
Building Code has no grade such as "paint grade pine" and calls
for a
12% moisture limit in lumber.
This condition is achieved
by kiln drying and in his opinion the finish supplied was not
kiln dried.
He estimated that to tear out the wood trim
complained of, and to replace it with proper material would
cost $2,900.00 and I
am allowing that item on the Defendant's
•
counter-claim.
-
6
Notwithstanding that the original tender
made by the Plaintiff excluded electrical work, it does
appear that at some stage the Defendant requested the Plaintiff
to put up light fixtures.
Mr. Banks testified that he engaged
a qualified electrician to put up these lights which were
described as "pot lamps".
These consisted of dome shaped
shades that were inserted in the ceiling to produce a flood
light effect.
Apparently the pot lights installed, which were
21 in number, were indentified in the specifications as
number 9660.
What was installed was lamp number 9655.
The
specified lamp was more expensive according to the evidence
of Martin Giddy and incorporated a small coil underneath the
lamp.
The Defendant complained that not only were the lamps
supplied not the specified ones, but that difficulty was
expressed with their operation in that two of the lights fell
down, and they were generally difficult to service.
In the
Plaintiff's rebuttal evidence Mr. Ted Rice the electrician
on the job frankly said, "I would like to see a better type
light.~
It appeared that all that was holding the light
up to the ceiling was the lip on the base of the lamp over
laping the base of the T-bar in the dropped ceiling.
If the
T-bar spread, the lamp would naturally fall down, and that is
what happened to two of them.
Other complaints of the electrical
system related to poor workmanship in installing the 60 and
•
100 amp panels, in particular they were not mounted flush with
-
7
the wall.
There is no doubt that the lamps did not meet
the specifications but there was no evidence presented to
the Court as to the cost of rectifyin~ the departure from
the specifications.
There is no way that I
can make a
satisfactory assessment of what the Defendant suffered, if
anything, by this failure on the part of the Plaintiff.
The
best I
can do is to allow a nominal amount only in respect of
it.
Giving the matter my best consideration and giving con
sideration to the amounts claimed for extras relating to the
ceiling lighting, I fix the sum as $500.00 as being due to the
Defendant as a credit.
The Defendant claims that in the dental
operating room the Plaintiff was to run cement on the floor
to bury the plumbing pipes.
Apparently the job turned out
to be a very rough one and at the request of Dr. Boudreau,
Mr. Banks took a grinding machine and smoothed it down to a
considerable extent.
However it became necessary to cut a
trench in the concrete floor to lay a pipe in it.
After this,
the floor was not built up again, but a carpet was laid on
it with the result that Dr. Boudreau complained that the
carpet was giving way over the small trench making it very
difficult for him to move about on a dental stool around his
operating equipment.
Having viewed the situation myself I
consider that an expenditure of $100.00 would correct this
particular defect but of course one would have to take into
-
8
account that the dental operating room could not be used
for the period of repairs and for this I
would allow a further
sum of $100.00.
The Defendant claims that the Plaintiff in
constructing a hallway in the premises put the walls of the
same up out of square.
Mr. Purdy estimated that it would cost
at least $1,000.00 to level out the walls.
Mr. Banks evidence
was that when they set about to put up the new walls as pro
vided in the plans they found a steel carrying post in such
a position that it was impossible to lay the hall out in a
straight line.
He said that he made this fact known to the
Defendant.
I
can only conclude that it must have been decided
to avoid the expense and structural hazard of removing the
carrying post and to proceed to build the wall as I
saw it
in the view I took of the premises.
I
do not believe it would
be fair to condemn the Plaintiff for the estimated cost of
straightening out that wall nor do I think that it detracts
in a material way from the general appearance of the premises.
The Counter-claim of the Defendant sets out
certain other defects which were very minor in nature and
relate to such things as proper fittings and rings not being
placed on plumbing pipes; shelves omitted in the storage
room and hallway as provided in the plans; some very minor
defects in connection with the cedar lamination on the front
-
9
of the building; a damaged countertop and some shut off
valves missing in the plumbing.
Again no evidence was
adduced before me as to what it would cost to remedy these
small defects and again having viewed the premises I can only
make my best estimates that $400.00 would cover all of these
items.
The Defendant also complained that the crack
filling on the gyprock paneling was poorly done and with that
I
would agree.
It had been provided for as an extra, having
been excluded from the original tenders.
For this I
would
allow the
sum of $400.00.
In fixing this amount I
am
taking into account that Mr. Banks testified that they had
taken on only the rough crackfilling job and had nothing to do
with the finish crackfilling.
He took the position that
that was the province of the painters who were employed
separate and apart from his firm.
The evidence of Robert Purdy was that the
plans and specifications for the job specifically provided
for solid birch doors.
The doors supplied were mahogany
and Purdy estimated that it would take $2,000.00 to replace
the doors as specified and I allow that credit to the Defendant.
He also testified that the normal practise was for the
contractor who has undertaken to supply and install doors to
also supply the door jams, hinges and lock sets.
The Plaintiff
-
10
had billed the Defendant for this hardware and door jams
I
in the amount of $1,915.91 as an extra.
In my view the
charges for that material were of necessity part and parcel
of the tender price and that latter amount is allowed as a
credit to the Defendant.
It is fair to say that through out there were
some deviations of the original arrangements made between
the Defexentand Plaintiff.
The original tender excluded
crackfilling, plumbing and electrical work but the Plaintiff
wound up doing some of this work and as was laid down in
Felch vs. Ritchie
(1882)
15 N.S.R. 407 (C.A.),a decision
of the Nova Scotia Court of Appeal, where there are deviations
to the extent that are apparent in this case,
"The Plaintiff was not entitled to recover
on the contract but was compelled to rely
on a quantum meruit".
Giving the claim of the Plaintiff the best
consideration I
can and being considerably hampered by the
lack of specific evidence as to the cost of bringing the
work up to a satisfactory condition, I
have come to the
following conclusions as to what portion of the Plaintiff's
claim ought to be allowed:
(a)
Amount owed to the Plaintiff per
Statement of Claim
$16,049.57
(b)
Less Credits or offsets due to
'
the Defendant:
-
11
(1)
Deviation in ceiling
height
I
$ 1,000.00
(2)
Difference in price of
ceiling tile specified
and that which was in
stalled
$ 1,155.90
(3)
Replacement of wood trim
$ 2,900.00
(4)
Deficiency in ceiling
lighting
$
500.00
(5)
Deficiency in dental
operating room
$
200.00
(6)
Minor deficiencies as
set out in page 9 hereof
$
400.00
(7)
Poor quality crackfilling
$
400.00
(8)
Replacement of doors
$ 2,000.00
(9)
Cost of hardware for
doors and door jams
$ 1,915.91
$10,471.81
$10,471.81
BALANCE
$ 5,577.76
The Plaintiff shall have judgment for the
sum of $5,577.76 together with 75% of its costs to be taxed.
The Defendant shall have 50% of its costs of the Counter-claim.
DATED at Annapolis Royal, Nova Scotia, this
28th day of September, A.D. 1982.
JUDGE OF THE COUNTY COURT
OF
DISTRICT NUMBER THREE
-
12
TO:
The Clerk of the Court,
The Court House,
Digby, Nova Scotia
Charles E. Haliburton, Q.C.,
Barrister and Solicitor,
P. o. Box 577,
Digby, Nova Scotia
BOV lAO
w. Michael Cooke, Esq.,
Barrister and Solicitor,
6464 Chebucto Road,
Halifax, Nova Scotia
B3L lL4
1979
IN THE
COUNTY COURT OF DISTRICT NUMBER THREE
BETWEEN:
DIGBY WOODWORKERS
-
and -
BASIN PLACE LIMITED
APPENDIX NO.1
C. D. No.
1009
LIMITED
PLAINTIFF
DEFENDANT
.r>
.
.T
.. !\il
.."..
SMITH'S COVE, N. S.
BOS 1S0
:.'iarch 6.
1978
Basin Place Ltd.
DiSby, N.S.
~e es~l~ate the cost of renovations to be as follows:
2enovat~ons for Basin Place Ltd.
$12~17$40
T
•
~G.DOU~
8654.80
x on material
977032
TOi:.al estimate
~;21849.59
Yours very truly
Digby Woodworkers Ltd.
Lawrence K.
Banks
President
Please noi:.e: Cost of door jambs not included in above price
Price does not include plum~ing & electrical work.
Crackfilling for above renovations will be $1175.68
~Q DAY
OF
-'-t;;;;;..l-LL...._. 19b~
SMITH'S COVE,
N. S.
BOS ISO
March 6, 1978
Basin Place Ltd ..
Digby, N.S.
Dear Sir:
Vie estimate the cost of dental office fiOD Dr. Boudreau to be
as fol101<7S:
:i.'Ia terlal
$8982.S2
Labour
2156.00
Tax.
718.63
Total estimate
$11857.45
Yours very truly
Digby ~oodworkers Ltd~
Lawrence K.
Banks
President
Please Note: Price does not include plumbing & electrical work
Crackfilling for Dr. Boudreau's office will be $334.40.
SMiTH'S COVE. N, S.
BOS ISO
I'1arch 6,
1978
3f1sin Place Ltd.
Digby. N.S.
:Jear Sir:
We estimate the cost of the Dental Technicians office to
be as follows:
11a terial
$4718.82
Labour
904.00
Tax
377 .. ')1
Total estimate
~6000.33
Yours very :truly
Digby Hoodworkers Ltd
~~' /~ /-:;
,1:
.'
'
'~,/"/J
Lawrence K.
Eanks
President
Please note: Price does not include plumbing and electrical work
EXHIBIT NO. 4(1/
-'--"'--'
(;~)cfurzl'hiO VS. &~'-RaeL
CASE
NO. eN IOQ9
10 DAY OF
cW. ,198;;_
CLERK
OF THE COURT
1.y2Jti£c i, (; Q,
DfGBV rJOODt'~OR[{ERS LID.
SMITH'S COVE, N. S.
BOS ISO
March 6,
1978
3asin Place Ltd.
Digby, N.S.
LJear 3ir:
We estimate the cost of the Lawyers office to be as follows:
l':aterial
~2J6J.29
Labour
2187.00
Tax
189.06
Total estimate
$4739.35
Yours very truly
Digby Wooeworkers Ltd.
/;;y/~-?,L
Lawrence K. Banks
President
Please note: Price does not include plumbing and electrical work.
Crackfilling for above office $281.60.
EXHIBIT
NO. #,0---
iJ-bcR,cnrzll');';V5./lz0;'" r2~t~
CAS END. t:.L~~o,-"o,-,9,--~
tODAY DF.i:'{,"
,19&\.2
CLERK
OF THE
COURT
A
('-L)
.
-JJi~l fLU?, <' L
You are being directed to the most recent version of the statute which may not be the version considered at the time of the judgment.